Rooster Construction

Professional Contractor Agreement

Contractor – Subcontractor Agreement

This Agreement is made and entered into on this , by and between:

General Contractor:

Name:

Business Name:

Address:

Phone:

Email:

Subcontractor:

Name:

Business Name:

Address:

Phone:

Email:

1. Scope of Work

Subcontractor agrees to furnish all labor, materials, tools, and equipment necessary to perform the following work:

Description of Work:

Work shall be performed in accordance with plans and specifications provided by the General Contractor.

2. Project Location

3. Compensation

Contract Amount ($):

Payment Schedule:

50% at start / 50% at completion Progress payments every days Paid in full upon satisfactory completion

Invoice Submission Email:

Payment Terms (business days to pay):

4. Timeline

Start Date:

Completion Date:

Delays caused by weather, material shortages, or other uncontrollable events must be communicated in writing.

5. Licensing and Insurance

Required Insurance Coverage ($):

License Number (if applicable):

7. Workmanship and Warranty

Warranty Period (years):

9. Dispute Resolution

Mediation Arbitration Legal action in the county of project location

contract generator